Privacy Policy

1.         Definitions

1.1       “Rob Martin Electrical” means RKCM Pty Ltd ATF R & K Martin Family Trust T/A Rob Martin Electrical, its successors and assigns or any person acting on behalf of and with the authority of RKCM Pty Ltd ATF R & K Martin Family Trust T/A Rob Martin Electrical.

1.2       “Client” means the person/s ordering the Works as specified in any invoice, document or order, and if there is more than one Client is a reference to each Client jointly and severally.

1.3       “Works” means all Works or Materials supplied by Rob Martin Electrical to the Client at the Client’s request from time to time (where the context so permits the terms ‘Works’ or ‘Materials’ shall be interchangeable for the other).

1.4       “Price” means the Price payable for the Works as agreed between Rob Martin Electrical and the Client in accordance with clause 4 below.

 

2.         Acceptance

2.1       The Client is taken to have exclusively accepted and is immediately bound, jointly and severally, by these terms and conditions if the Client places an order for or accepts delivery of any Works.

2.2       These terms and conditions may only be amended with Rob Martin Electrical’s consent in writing and shall prevail to the extent of any inconsistency with any other document or agreement between the Client and Rob Martin Electrical.

2.3      These terms and conditions are meant to be read in conjunction with the Terms and Conditions posted on Rob Martin Electrical’s website. If there are any inconsistencies between the two documents then the terms and conditions contained in this document shall prevail.

 

3.         Change in Control

3.1       The Client shall give Rob Martin Electrical not less than fourteen (14) days prior written notice of any proposed change of ownership of the Client and/or any other change in the Client’s details (including but not limited to, changes in the Client’s name, address, contact phone or fax number/s, or business practice). The Client shall be liable for any loss incurred by Rob Martin Electrical as a result of the Client’s failure to comply with this clause.

 

4.         Price and Payment

4.1       At Rob Martin Electrical’s sole discretion the Price shall be either:

(a)  as indicated on invoices provided by Rob Martin Electrical to the Client in respect of Works performed or Materials supplied; or

(b) Rob Martin Electrical’s quoted Price (subject to clause 4.2) which shall be binding upon Rob Martin Electrical provided that the Client shall accept Rob Martin Electrical’s quotation in writing within thirty (30) days.

4.2       Rob Martin Electrical reserves the right to change the Price:

(a)  if a variation to the Materials which are to supplied is requested; or

(b) if a variation to the Works originally scheduled (including any applicable plans or specifications) is requested; or

(c)  where additional Works are required due to the discovery of hidden or unidentifiable difficulties (including, but not limited to, hard rock barriers below the surface, iron reinforcing rods in concrete, or hidden pipes and wiring in walls, roof reinforcing required for installations, replacement, repair or suitability of existing plumbing fittings, flues, piping, floor covering, wiring, roofing or any other household effect etc) which are only discovered on commencement of the Works; or

(d) in the event of increases to Rob Martin Electrical in the cost of labour or materials which are beyond Rob Martin Electrical’s control.

4.3       At Rob Martin Electrical’s sole discretion a non-refundable deposit may be required.

4.4       Time for payment for the Works being of the essence, the Price will be payable by the Client on the date/s determined by Rob Martin Electrical, which may be:

(a)  on completion of the Works; or

(b) before delivery of the Materials;

(c)  by way of progress payments in accordance with Rob Martin Electrical’s specified progress payment schedule. Such progress payment claims may include the reasonable value of authorised variations and the value of any Materials delivered to the site but not yet installed;

(d) the date specified on any invoice or other form as being the date for payment; or

(e)  failing any notice to the contrary, the date which is seven (7) days following the date of any invoice given to the Client by Rob Martin Electrical.

4.5       Payment may be made by cash, cheque, bank cheque, electronic/on-line banking, credit card (plus a surcharge of up to three percent (3%) of the Price), or by any other method as agreed to between the Client and Rob Martin Electrical.

4.6       Unless otherwise stated the Price does not include GST. In addition to the Price the Client must pay to Rob Martin Electrical an amount equal to any GST Rob Martin Electrical must pay for any supply by Rob Martin Electrical under this or any other agreement for the sale of the Materials. The Client must pay GST, without deduction or set off of any other amounts, at the same time and on the same basis as the Client pays the Price. In addition the Client must pay any other taxes and duties that may be applicable in addition to the Price except where they are expressly included in the Price.

 

5.         Delivery of the Works

5.1       Delivery (“Delivery”) of the Materials is taken to
occur at the time that:

(a)  the Client or the Client’s nominated carrier takes possession of the Materials at Rob Martin Electrical’s address; or

(b) Rob Martin Electrical (or Rob Martin Electrical’s nominated carrier) delivers the Materials to the Client’s nominated address even if the Client is not present at the address.

5.2       At Rob Martin Electrical’s sole discretion the cost of delivery is either included in the Price or is in addition to the Price.

5.3       The Client must take delivery by receipt or collection of the Materials whenever they are tendered for delivery. In the event that the Client is unable to take delivery of the Materials as arranged then Rob Martin Electrical shall be entitled to charge a reasonable fee for redelivery and/or storage.

5.4       Subject to clause 5.5 it is Rob Martin Electrical’s responsibility to ensure that the Works start as soon as it is reasonably possible.

5.5       The Works commencement date will be put back and/or the completion date extended by whatever time is reasonable in the event that Rob Martin Electrical claims an extension of time (by giving the Client written notice) where completion is delayed by an event beyond Rob Martin Electrical’s control, including but not limited to any failure by the Client to:

(a)  make a selection; or

(b) have the site ready for the Works; or

(c)  notify Rob Martin Electrical that the site is ready.

5.6       Rob Martin Electrical may deliver the Works by separate instalments. Each separate instalment shall be invoiced and paid in accordance with the provisions in these terms and conditions.

5.7       Any time or date given by Rob Martin Electrical to the Client is an estimate only. Rob Martin Electrical shall not be liable for any loss or damage whatsoever due to failure by Rob Martin Electrical to deliver the Works (or any part of them) promptly or at all, where due to circumstances beyond the reasonable control of Rob Martin Electrical.

 

6.         Risk

6.1       If Rob Martin Electrical retains ownership of the Materials under clause 6.3 then;

(a)  where Rob Martin Electrical is supplying Materials only, all risk for the Materials shall immediately pass to the Client on delivery and the Client must insure the Materials on or before delivery. Delivery of the Materials shall be deemed to have taken place immediately at the time that either;

(i)   the Client or the Client’s nominated carrier takes possession of the Materials at Rob Martin Electrical’s address; or

(ii)  the Materials are delivered by Rob Martin Electrical or Rob Martin Electrical’s nominated carrier to the Client’s nominated delivery address (even if the Client is not present at the address).

(b) where Rob Martin Electrical is to both supply and install Materials then Rob Martin Electrical shall maintain a contract works insurance policy until the Works are completed. Upon completion of the Works all risk for the Works shall immediately pass to the Client.

6.2       Notwithstanding the provisions of clause 6.1 if the Client specifically requests Rob Martin Electrical to leave Materials outside Rob Martin Electrical’s premises for collection or to deliver the Materials to an unattended location then such materials shall always be left at sole risk of the Client and it shall be the Client’s responsibility to ensure the Materials are insured adequately or at all. In the event that such Materials are lost, damaged or destroyed then replacement of the Materials shall be at the Client’s expense.

6.3       Installation costs set out on an attached quotation (if any) are based on the methods and procedures as agreed between Rob Martin Electrical and the Client and/or outlined on the attached quotation.  In the event that the Client requests changes to these methods and procedures, Rob Martin Electrical shall be entitled to charge for additional costs and/or work involved.

6.4       Rob Martin Electrical shall not be liable for any loss or damage whatsoever in relation to replacement, repair, or suitability of existing plumbing fittings, pumps and fittings, controllers, flue, piping, floor covering, wiring, roofing or any other household effect.

6.5       The Client acknowledges and agrees that any quoted Price is based on the condition that any existing roofing, plumbing and wiring is in good condition, in a good state of repair, and in accordance with the current requirements of gas, electric or water authorities.  The Client also agrees to indemnify Rob Martin Electrical against any and all damages, loss or costs however arising resulting from the existing roofing, plumbing and wiring not being in a good condition, good state of repair, or not in accordance with the current requirements of gas, electric or water authorities.

6.6       The Client acknowledges and agrees that any quoted Price excludes; any roof reinforcing required for solar installations, and any certification on roof designs.

 

7.         Air-Conditioning Risk

7.1       The final location of the wall, window or floor unit must be determined on site by the Client.

7.2       The Client acknowledges and agrees that Rob Martin Electrical does not guarantee any noise levels (external or internal) and Rob Martin Electrical shall not be held liable for any loss, damages, or costs, however resulting from noise levels.

7.3       In the event that any of the equipment needs to be relocated due to complaints from neighbours or local authorities, then the Client shall be responsible for any and all costs involved.

7.4       The Client acknowledges and agrees that it is their responsibility to insure any equipment partly or completely installed on site, against theft or damage.

7.5       In the event that the electrical wiring is required to be re-positioned at the request of any third party contracted by the Client then the Client agrees to notify Rob Martin Electrical immediately upon any proposed changes.  The Client agrees to indemnify Rob Martin Electrical against any additional costs incurred with such a relocation of electrical wiring.  All such variances shall be invoiced in accordance with clause 4.2.

 

8.         Access

8.1       The Client shall ensure that Rob Martin Electrical has clear and free access to the work site at all times to enable them to undertake the works. Rob Martin Electrical shall not be liable for any loss or damage to the site (including, without limitation, damage to pathways, driveways and concreted or paved or grassed areas) unless due to the negligence of Rob Martin Electrical.

 

9.         Underground Locations

9.1       Prior to Rob Martin Electrical commencing any work the Client must advise Rob Martin Electrical of the precise location of all underground services on the site and clearly mark the same. The underground mains & services the Client must identify include, but are not limited to, electrical services, gas services, sewer services, pumping services, sewer connections, sewer sludge mains, water mains, irrigation pipes, telephone cables, fibre optic cables, oil pumping mains, and any other services that may be on site.

9.2       Whilst Rob Martin Electrical will take all care to avoid damage to any underground services the Client agrees to indemnify Rob Martin Electrical in respect of all and any liability claims, loss, damage, costs and fines as a result of damage to services not precisely located and notified as per clause 9.1.

 

10.       Title

10.1     Rob Martin Electrical and the Client agree that ownership of the Materials shall not pass until:

(a)  the Client has paid Rob Martin Electrical all amounts owing to Rob Martin Electrical; and

(b) the Client has met all of its other obligations to Rob Martin Electrical.

10.2     Receipt by Rob Martin Electrical of any form of payment other than cash shall not be deemed to be payment until that form of payment has been honoured, cleared or recognised.

10.3     It is further agreed that:

(a)  until ownership of the Materials passes to the Client in accordance with clause 10.1 that the Client is only a bailee of the Materials and unless the Materials have become fixtures must return the Materials to Rob Martin Electrical on request.

(b) the Client holds the benefit of the Client’s insurance of the Materials on trust for Rob Martin Electrical and must pay to Rob Martin Electrical the proceeds of any insurance in the event of the Materials being lost, damaged or destroyed.

(c)  the production of these terms and conditions by Rob Martin Electrical shall be sufficient evidence of Rob Martin Electrical’s rights to receive the insurance proceeds direct from the insurer without the need for any person dealing with Rob Martin Electrical to make further enquiries.

(d) the Client must not sell, dispose, or otherwise part with possession of the Materials other than in the ordinary course of business and for market value. If the Client sells, disposes or parts with possession of the Materials then the Client must hold the proceeds of any such act on trust for Rob Martin Electrical and must pay or deliver the proceeds to Rob Martin Electrical on demand.

(e)  the Client should not convert or process the Materials or intermix them with other Materials but if the Client does so then the Client holds the resulting product on trust for the benefit of Rob Martin Electrical and must sell, dispose of or return the resulting product to Rob Martin Electrical as it so directs.

(f)  unless the Materials have become fixtures the Client irrevocably authorises Rob Martin Electrical to enter any premises where Rob Martin Electrical believes the Materials are kept and recover possession of the Materials.

(g) Rob Martin Electrical may recover possession of any Materials in transit whether or not delivery has occurred.

(h)  the Client shall not charge or grant an encumbrance over the Materials nor grant nor otherwise give away any interest in the Materials while they remain the property of Rob Martin Electrical.

(i)   Rob Martin Electrical may commence proceedings to recover the Price of the Materials sold notwithstanding that ownership of the Materials has not passed to the Client.

 

11.       Personal Property Securities Act 2009 (“PPSA”)

11.1     In this clause financing statement, financing change statement, security agreement, and security interest has the meaning given to it by the PPSA.

11.2     Upon assenting to these terms and conditions in writing the Client acknowledges and agrees that these terms and conditions constitute a security agreement for the purposes of the PPSA and creates a security interest in all Materials that have previously been supplied and that will be supplied in the future by Rob Martin Electrical to the Client.

11.3     The Client undertakes to:

(a)  promptly sign any further documents and/or provide any further information (such information to be complete, accurate and up-to-date in all respects) which Rob Martin Electrical may reasonably require to:

(i)   register a financing statement or financing change statement in relation to a security interest on the Personal Property Securities Register;

(ii)  register any other document required to be registered by the PPSA; or

(iii) correct a defect in a statement referred to in clause 11.3(a)(i) or 11.3(a)(ii);

(b) indemnify, and upon demand reimburse, Rob Martin Electrical for all expenses incurred in registering a financing statement or financing change statement on the Personal Property Securities Register established by the PPSA or releasing any Materials charged thereby;

(c)  not register a financing change statement in respect of a security interest without the prior written consent of Rob Martin Electrical;

(d) not register, or permit to be registered, a financing statement or a financing change statement in relation to the Materials in favour of a third party without the prior written consent of Rob Martin Electrical; and

(e)  immediately advise Rob Martin Electrical of any material change in its business practices of selling the Materials which would result in a change in the nature of proceeds derived from such sales.

11.4     Rob Martin Electrical and the Client agree that sections 96, 115 and 125 of the PPSA do not apply to the security agreement created by these terms and conditions.

11.5     The Client hereby waives its rights to receive notices under sections 95, 118, 121(4), 130, 132(3)(d) and 132(4) of the PPSA.

11.6     The Client waives its rights as a grantor and/or a debtor under sections 142 and 143 of the PPSA.

11.7     Unless otherwise agreed to in writing by Rob Martin Electrical, the Client waives its right to receive a verification statement in accordance with section 157 of the PPSA.

11.8     The Client shall unconditionally ratify any actions taken by Rob Martin Electrical under clauses 11.3 to 11.5.

11.9     Subject to any express provisions to the contrary nothing in these terms and conditions is intended to have the effect of contracting out of any of the provisions the PPSA.

 

12.       Security and Charge

12.1     In consideration of Rob Martin Electrical agreeing to supply the Materials, the Client charges all of its rights, title and interest (whether joint or several) in any land, realty or other assets capable of being charged, owned by the Client either now or in the future, to secure the performance by the Client of its obligations under these terms and conditions (including, but not limited to, the payment of any money).

12.2     The Client indemnifies Rob Martin Electrical from and against all Rob Martin Electrical’s costs and disbursements including legal costs on a solicitor and own client basis incurred in exercising Rob Martin Electrical’s rights under this clause.

12.3     The Client irrevocably appoints Rob Martin Electrical and each director of Rob Martin Electrical as the Client’s true and lawful attorney/s to perform all necessary acts to give effect to the provisions of this clause 12 including, but not limited to, signing any document on the Client’s behalf.

 

13.       Defects, Warranties and Returns, Competition and Consumer Act 2010 (CCA)

13.1     The Client must inspect all Materials on delivery (or the Works on completion) and must within seven (7) days of delivery notify Rob Martin Electrical in writing of any evident defect/damage, shortage in quantity, or failure to comply with the description or quote. The Client must notify any other alleged defect in the Materials/Works as soon as reasonably possible after any such defect becomes evident. Upon such notification the Client must allow Rob Martin Electrical to inspect the Materials or to review the Works provided.

13.2     Under applicable State, Territory and Commonwealth Law (including, without limitation the CCA), certain statutory implied guarantees and warranties (including, without limitation the statutory guarantees under the CCA) may be implied into these terms and conditions (Non-Excluded Guarantees).

13.3     Rob Martin Electrical acknowledges that nothing in these terms and conditions purports to modify or exclude the Non-Excluded Guarantees.

13.4     Except as expressly set out in these terms and conditions or in respect of the Non-Excluded Guarantees, Rob Martin Electrical makes no warranties or other representations under these terms and conditions including but not limited to the quality or suitability of the Materials/Works. Rob Martin Electrical’s liability in respect of these warranties is limited to the fullest extent permitted by law.

13.5     If the Client is a consumer within the meaning of the CCA, Rob Martin Electrical’s liability is limited to the extent permitted by section 64A of Schedule 2.

13.6     If Rob Martin Electrical is required to replace any Materials under this clause or the CCA, but is unable to do so, Rob Martin Electrical may refund any money the Client has paid for the Materials.

13.7     If Rob Martin Electrical is required to rectify, re-supply, or pay the cost of re-supplying the Works under this clause or the CCA, but is unable to do so, then Rob Martin Electrical may refund any money the Client has paid for the Works but only to the extent that such refund shall take into account the value of Works and Materials which have been provided to the Client which were not defective.

13.8     If the Client is not a consumer within the meaning of the CCA, Rob Martin Electrical’s liability for any defect or damage in the Materials is:

(a)  limited to the value of any express warranty or warranty card provided to the Client by Rob Martin Electrical at Rob Martin Electrical’s sole discretion;

(b) limited to any warranty to which Rob Martin Electrical is entitled, if Rob Martin Electrical did not manufacture the Materials;

(c)  otherwise negated absolutely.

13.9     Subject to this clause 13, returns will only be accepted provided that:

(a)  the Client has complied with the provisions of clause 13.1; and

(b) Rob Martin Electrical has agreed that the Materials are defective; and

(c)  the Materials are returned within a reasonable time at the Client’s cost (if that cost is not significant); and

(d) the Materials are returned in as close a condition to that in which they were delivered as is possible.

13.10  Notwithstanding clauses 13.1 to 13.9 but subject to the CCA, Rob Martin Electrical shall not be liable for any defect or damage which may be caused or partly caused by or arise as a result of:

(a)  the Client failing to properly maintain or store any Materials;

(b) the Client using the Materials for any purpose other than that for which they were designed;

(c)  the Client continuing to use any Materials after any defect became apparent or should have become apparent to a reasonably prudent operator or user;

(d) interference with the Works by the Client or any third party without Rob Martin Electrical’s prior approval;

(e)  the Client failing to follow any instructions or guidelines provided by Rob Martin Electrical;

(f)  fair wear and tear, any accident, or act of God.

13.11  In the case of second hand Materials, unless the Client is a consumer under the CCA, the Client acknowledges that it has had full opportunity to inspect the second hand Materials prior to delivery and accepts them with all faults and that to the extent permitted by law no warranty is given by Rob Martin Electrical as to the quality or suitability for any purpose and any implied warranty, statutory or otherwise, is expressly excluded. The Client acknowledges and agrees that Rob Martin Electrical has agreed to provide the Client with the second hand Materials and calculated the Price of the second hand Materials in reliance of this clause 13.11.

13.12  Notwithstanding anything contained in this clause if Rob Martin Electrical is required by a law to accept a return then Rob Martin Electrical will only accept a return on the conditions imposed by that law.

14.       Default and Consequences of Default

14.1     Interest on overdue invoices shall accrue daily from the date when payment becomes due, until the date of payment, at a rate of two and a half percent (2.5%) per calendar month (and at Rob Martin Electrical’s sole discretion such interest shall compound monthly at such a rate) after as well as before any judgment.

14.2     If the Client owes Rob Martin Electrical any money the Client shall indemnify Rob Martin Electrical from and against all costs and disbursements incurred by Rob Martin Electrical in recovering the debt (including but not limited to internal administration fees, legal costs on a solicitor and own client basis, Rob Martin Electrical’s collection agency costs, and bank dishonour fees).

14.3     Without prejudice to any other remedies Rob Martin Electrical may have, if at any time the Client is in breach of any obligation (including those relating to payment) under these terms and conditions Rob Martin Electrical may suspend or terminate the supply of Works to the Client. Rob Martin Electrical will not be liable to the Client for any loss or damage the Client suffers because Rob Martin Electrical has exercised its rights under this clause.

14.4     Without prejudice to Rob Martin Electrical’s other remedies at law Rob Martin Electrical shall be entitled to cancel all or any part of any order of the Client which remains unfulfilled and all amounts owing to Rob Martin Electrical shall, whether or not due for payment, become immediately payable if:

(a)  any money payable to Rob Martin Electrical becomes overdue, or in Rob Martin Electrical’s opinion the Client will be unable to make a payment when it falls due;

(b) the Client becomes insolvent or bankrupt, convenes a meeting with its creditors or proposes or enters into an arrangement with creditors, or makes an assignment for the benefit of its creditors; or

(c)  a receiver, manager, liquidator (provisional or otherwise) or similar person is appointed in respect of the Client or any asset of the Client.

 

15.       Compliance with Laws

15.1     All work will be tested to ensure that it is electrically safe and is in accordance with the wiring rules and other standards applying to the electrical installation under the Electrical Safety Regulations 2002.  All of the cabling work will comply with the Australian and New Zealand Wiring standards.

15.2     The Client shall obtain (at the expense of the Client) all licenses, approvals, applications and permits that may be required for the works, and that are not included in the project documents provided by Rob Martin Electrical

15.3     The Client agrees that the site will comply with any occupational health and safety laws relating to building/construction sites and any other relevant safety standards or legislation.

 

16.       Cancellation

16.1     Rob Martin Electrical may cancel any contract to which these terms and conditions apply or cancel delivery of Works at any time before the Works are commenced by giving written notice to the Client. On giving such notice Rob Martin Electrical shall repay to the Client any sums paid in respect of the Price, less any amounts owing by the Client to Rob Martin Electrical for Works already performed. Rob Martin Electrical shall not be liable for any loss or damage whatsoever arising from such cancellation.

16.2     In the event that the Client cancels the delivery of Works the Client shall be liable for any and all loss incurred (whether direct or indirect) by Rob Martin Electrical as a direct result of the cancellation (including, but not limited to, any loss of profits).

16.3     Cancellation of orders for products made to the Client’s specifications, or for non-stocklist items, will definitely not be accepted once production has commenced, or an order has been placed.

 

17.       Privacy Act 1988

17.1     The Client agrees for Rob Martin Electrical to obtain from a credit reporting agency a credit report containing personal credit information about the Client in relation to credit provided by Rob Martin Electrical.

17.2     The Client agrees that Rob Martin Electrical may exchange information about the Client with those credit providers either named as trade referees by the Client or named in a consumer credit report issued by a credit reporting agency for the following purposes:

(a)  to assess an application by the Client; and/or

(b) to notify other credit providers of a default by the Client; and/or

(c)  to exchange information with other credit providers as to the status of this credit account, where the Client is in default with other credit providers; and/or

(d) to assess the creditworthiness of the Client.

The Client understands that the information exchanged can include anything about the Client’s creditworthiness, credit standing, credit history or credit capacity that credit providers are allowed to exchange under the Privacy Act 1988.

17.3     The Client consents to Rob Martin Electrical being given a consumer credit report to collect overdue payment on commercial credit (Section 18K(1)(h) Privacy Act 1988).

17.4     The Client agrees that personal credit information provided may be used and retained by Rob Martin Electrical for the following purposes (and for other purposes as shall be agreed between the Client and Rob Martin Electrical or required by law from time to time):

(a)  the provision of Works; and/or

(b) the marketing of Works by Rob Martin Electrical, its agents or distributors; and/or

(c)  analysing, verifying and/or checking the Client’s credit, payment and/or status in relation to the provision of Works; and/or

(d) processing of any payment instructions, direct debit facilities and/or credit facilities requested by the Client; and/or

(e)  enabling the daily operation of Client’s account and/or the collection of amounts outstanding in the Client’s account in relation to the Works.

17.5     Rob Martin Electrical may give information about the Client to a credit reporting agency for the following purposes:

(a)  to obtain a consumer credit report about the Client;

(b) allow the credit reporting agency to create or maintain a credit information file containing information about the Client.

17.6     The information given to the credit reporting agency may include:

(a)  personal particulars (the Client’s name, sex, address, previous  addresses, date of birth, name of employer and driver’s licence number);

(b) details concerning the Client’s application for credit or commercial credit and the amount requested;

(c)  advice that Rob Martin Electrical is a current credit provider to the Client;

(d) advice of any overdue accounts, loan repayments, and/or any outstanding monies owing which are overdue by more than sixty (60) days, and for which debt collection action has been started;

(e)  that the Client’s overdue accounts, loan repayments and/or any outstanding monies are no longer overdue in respect of any default that has been listed;

(f)  information that, in the opinion of Rob Martin Electrical, the Client has committed a serious credit infringement (that is, fraudulently or shown an intention not to comply with the Client’s credit obligations);

(g) advice that cheques drawn by the Client for one hundred dollars ($100) or more, have been dishonoured more than once;

(h)  that credit provided to the Client by Rob Martin Electrical has been paid or otherwise discharged.

 

18.       Unpaid Rob Martin Electrical’s Rights

18.1     Where the Client has left any item with Rob Martin Electrical for repair, modification, exchange or for Rob Martin Electrical to perform any other service in relation to the item and Rob Martin Electrical has not received or been tendered the whole of any moneys owing to it by the Client, Rob Martin Electrical shall have, until all moneys owing to Rob Martin Electrical are paid:

(a)  a lien on the item; and

(b) the right to retain or sell the item, such sale to be undertaken in accordance with any legislation applicable to the sale or disposal of uncollected Materials.

18.2     The lien of Rob Martin Electrical shall continue despite the commencement of proceedings, or judgment for any moneys owing to Rob Martin Electrical having been obtained against the Client.

 

19.       Building and Construction Industry Payments Act 2004

19.1     At Rob Martin Electrical’s sole discretion, if there are any disputes or claims for unpaid Materials and/or Works then the provisions of the Building and Construction Industry Payments Act 2004 may apply.

19.2     Nothing in this agreement is intended to have the effect of contracting out of any applicable provisions of the Building and Construction Industry Payments Act 2004 of Queensland, except to the extent permitted by the Act where applicable.

 

20.       General

20.1     The failure by Rob Martin Electrical to enforce any provision of these terms and conditions shall not be treated as a waiver of that provision, nor shall it affect Rob Martin Electrical’s right to subsequently enforce that provision. If any provision of these terms and conditions shall be invalid, void, illegal or unenforceable the validity, existence, legality and enforceability of the remaining provisions shall not be affected, prejudiced or impaired.

20.2     These terms and conditions and any contract to which they apply shall be governed by the laws of the state in which Rob Martin Electrical has its principal place of business, and are subject to the jurisdiction of the courts in that state.

20.3     Subject to clause 13 Rob Martin Electrical shall be under no liability whatsoever to the Client for any indirect and/or consequential loss and/or expense (including loss of profit) suffered by the Client arising out of a breach by Rob Martin Electrical of these terms and conditions (alternatively Rob Martin Electrical’s liability shall be limited to damages which under no circumstances shall exceed the Price of the Works).

20.4     The Client shall not be entitled to set off against, or deduct from the Price, any sums owed or claimed to be owed to the Client by Rob Martin Electrical nor to withhold payment of any invoice because part of that invoice is in dispute.

20.5     Rob Martin Electrical may license or sub-contract all or any part of its rights and obligations without the Client’s consent.

20.6     The Client agrees that Rob Martin Electrical may amend these terms and conditions at any time. If Rob Martin Electrical makes a change to these terms and conditions, then that change will take effect from the date on which Rob Martin Electrical notifies the Client of such change. The Client will be taken to have accepted such changes if the Client makes a further request for Rob Martin Electrical to provide any Works to the Client.

20.7     Neither party shall be liable for any default due to any act of God, war, terrorism, strike, lock-out, industrial action, fire, flood, storm or other event beyond the reasonable control of either party.

20.8     The Client warrants that it has the power to enter into this agreement and has obtained all necessary authorisations to allow it to do so, it is not insolvent and that this agreement creates binding and valid legal obligations on it.

Instant Quote

ENTER SECURITY CODE
captcha

what clients say!

Rob Martin Electrical has exceptional professional service which cannot be beaten. Both financially competitive
Jacqui Kelly
Rob……………….. very happy with the work performed and the professionalism and work ethics displayed
Laurie Anderson
Hi Rob, We were delighted with your work. You listened to what we wanted
Keith
Rob did some Electrical work for us – he was punctual, professional and nice
Kirsty
Good morning Rob. I would also like to take this opportunity to thank you
Clay
Rob supplied and installed two Air-conditioners in my unit and they are amazing! I
Amanda, Paddington
Hi Rob, No job is too big or too small and you know what
Alphegé Browne
23 April 2013 Hi Rob, Both Danielle and myself would like to pass on
Lance and Dani Johnson
Rob has been our electrician since we purchased our first home approximately 9 months
Nick and Carly, Bald Hills
Very fast and very friendly!
Sue, Cleveland
5 REASONS TO CHOOSE >>
ROB MARTIN ELECTRICALS

GET IN TOUCH

0412083349
rob@robmartinelectrical.com.au
Ridge QLD 4017
SERVICE LOCATIONS